jQuery Mobile Framework
Search Home >> Standards Wordwide >> Australia Standards(AS) >> AS 2124, 2125, 2127-1986 general conditions of contract

AS 2124, 2125, 2127-1986 general conditions of contract

Standard Number:  AS 2124, 2125, 2127-1986
Title:  general conditions of contract
Language:  English
Replaced by Standard:  AS 2124, 2125, 2127-1992 (Reference Use Only)

Publication Date:  1986/7/14
Status:  Current
International Classification for Standards (ICS)CONSTRUCTION MATERIALS AND BUILDING>>Construction industry>>Contractual aspects
Publisher:  Australia Standards(AS)
Price:  
Number of Pages:39P.;A4  

Description:Comprises a single set of general conditions of contract suitable for a wide variety of civil engineering, building, electrical and mechanical engineering and other types of engineering and construction contracts. AS 2545-1986, Subcontract conditions, ha  
Catalog:Document Contents
AS 2124-1986 GENERAL CONDITIONS OF CONTRACT (AS 2124/A-1986 annexure part a AND AS 2127-...
PREFACE
CONTENTS
1 CONSTRUCTION OF CONTRACT.
2 INTERPRETATION.
3 NATURE OF CONTRACT.
3.1 Performance and Payment
3.2 Quantities
3.3 Omitted Items.
4 BILL OF QUANTITIES.
4.1 Purpose of the Bill of Quantities.
4.2 Lodgement.
4.3 Pricing.
5 SECURITY, RETENTION MONEYS AND PERFORMANCE UNDER-TAKINGS.
5.1 Purpose.
5.2 Provision of Security.
5.3 Form of Security.
5.4 Time for Lodgement of Security
5.5 Conversion of Security.
* 5.6 Substitution of Security for Retention Moneys.
* 5.7 Reduction of Security and Retention Moneys.
5.8 Release of Security.
5.9 Interest on Security and Retention Moneys.
6 EVIDENCE OF CONTRACT.
6.1 Contract in Absence of Formal Instrument of Agreement.
6.2 Formal Instrument of Agreement.
7 SERVICE OF NOTICES.
8 CONTRACT DOCUMENTS.
8.1 Discrepancies.
8.2 Dimensions.
8.3 Supply of documents by Principal.
8.4 Supply of Documents by Contractor.
8.5 Availability of Documents.
8.6 Confidential Information.
* 8.7 Media Releases.
9 ASSIGNMENT AND SUBCONTRACTING.
9.1 Assignment.
9.2 Subcontracting.
9.3 Contractor?s Responsibility.
10 DESIGNATED, SELECTED AND NOMINATED SUBCONTRACTORS.
10.1 Definitions.
10.2 Designated Subcontract.
10.3 Selected Subcontract.
10.4 Nominated Subcontract.
10.5 Provisions Applying Generally to Designated, Selected and Nominated Subcontract Work.
* 10.6 Direct Payment of Designated or Nominated Subcontractors.
10.7 Termination of Designated and Nominated Subcontracts.
11 PROVISIONAL SUMS.
12 LATENT CONDITIONS.
12.1 Definition.
12.2 Notification.
12.3 Extension of Time and Costs.
12.4 Time Bar.
13 PATENTS, COPYRIGHT AND OTHER INTELLECTUAL PROPERTY RIGHTS.
14 STATUTORY REQUIREMENTS.
14.1 Complying with Statutory Requirements.
* 14.2 Payment Where There is no Variation.
14.3 Notices and Fees.
14.4 Documents Evidencing Approvals of Authorities.
15 PROTECTION OF PEOPLE AND PROPERTY.
16 CARE OF THE WORK AND REINSTATEMENT OF DAMAGE.
16.1 Care of the Work Under the Contract.
16.2 Reinstatement.
16.3 Excepted Risks.
17 DAMAGE TO PERSONS AND PROPERTY OTHER THAN THE WORKS.
17.1 Indemnity by Contractor.
17.2 Indemnity by the Principal.
18 INSURANCE OF THE WORKS.
19 PUBLIC LIABILITY INSURANCE.
20 INSURANCE OF EMPLOYEES.
21 INSPECTION AND PROVISIONS OF INSURANCE POLICIES.
21.1 Proof of Insurance.
21.2 Failure to Produce Proof of Insurance.
21.3 Notices from or to the Insurer.
21.4 Notices of Potential Claims.
21.5 Settlement of Claims.
22 CLERK OF WORKS AND INSPECTORS.
23 SUPERINTENDENT.
24 SUPERINTENDENT?S REPRESENTATIVE.
25 CONTRACTOR?S REPRESENTATIVE.
26 CONTROL OF CONTRACTOR?S EMPLOYEES AND SUBCONTRACTORS.
27 SITE.
27.1 Possession of Site.
27.2 Access for the Principal and Others.
27.3 Delivery of Materials to and Work on Site Before Possession.
27.4 Use of Site by Contractor.
27.5 Finding of Minerals, Fossils and Relics.
28 SETTING OUT THE WORKS.
28.1 Setting Out.
28.2 Care of Survey Marks.
28.3 Errors in Setting Out.
28.4 Survey Mark Defined.
29 MATERIALS, LABOUR AND CONSTRUCTIONAL PLANT.
29.1 Provision of Materials, Labour and Constructional Plant.
29.2 Removal of Materials and Constructional Plant.
29.3 Manufacture and Supply of Materials.
30 MATERIALS AND WORK.
30.1 Quality of Materials and Work.
30.2 Defective Materials or Work.
30.3 Variations due to Defective Materials or Work.
30.4 Acceptance of Defective Material or Work.
30.5 Generally.
31 EXAMINATION AND TESTING.
31.1 Superintendent May Order Tests.
31.2 Covering Up of Work.
31.3 Who Conducts Tests.
31.4 Notice of Tests.
31.5 Procedure if Tests Delayed.
31.6 Results of Tests.
31.7 Costs of Testing.
32 WORKING HOURS.
33 PROGRESS AND PROGRAMMING OF THE WORKS.
33.1 Rate of Progress.
33.2 Construction Program.
34 SUSPENSION OF THE WORKS.
34.1 Suspension by Superintendent.
34.2 Suspension by Contractor.
34.3 Recommencement of Work.
34.4 Cost of Suspension.
34.5 Effect of Suspension.
35 TIMES FOR COMMENCEMENT AND PRACTICAL COMPLETION.
35.1 Time for Commencement of Work on the Site.
35.2 Time for Practical Completion.
35.3 Separable Portions.
35.4 Use of Partly Completed Works.
35.5 Extension of Time for Practical Completion.
35.6 Liquidated Damages for Delay in Reaching Practical Completion.
* 35.7 Limit on Liquidated Damages.
* 35.8 Bonus for Early Practical Completion.
* 36 DELAY COSTS.
37 DEFECTS LIABILITY.
38 CLEANING UP.
39 URGENT PROTECTION.
40 VARIATIONS.
40.1 Variations to the Work.
40.2 Valuation.
41 DAYWORK.
42 CERTIFICATES AND PAYMENTS.
42.1 Payment Claims, Payment Certificates and Time for Payment.
42.2 The Calculation of Payment.
42.3 Retention Moneys.
42.4 Unfixed Plant and Materials.
42.5 Certificate of Practical Completion.
42.6 Effect of Certificates.
42.7 Final Payment Claim.
42.8 Final Payment Certificate.
42.9 Interest on Overdue Payments.
42.10 Set Offs by the Principal.
43 PAYMENT OF WORKERS AND SUBCONTRACTORS.
44 DEFAULT OR INSOLVENCY.
44.1 Preservation of Other Rights.
44.2 Default by the Contractor.
44.3 Requirements of a Notice by the Principal to Show Cause.
44.4 Rights of the Principal.
44.5 Procedure when the Principal Takes Over Work.
44.6 Adjustment on Completion of the Work Taken Out of the Hands of the Contractor.
44.7 Default of the Principal.
44.8 Requirements of a Notice by the Contractor to Show Cause.
44.9 Rights of Contractor.
44.10 Rights of the Parties on Termination.
44.11 Insolvency.
* 45 TERMINATION BY FRUSTRATION.
46 DISPUTES.
46.1 Submission to the Superintendent.
46.2 Arbitration.
ANNEXURE to the Australian Standard General Conditions of Contract - Part A
ANNEXURE to the Australian Standard General Conditions of Contract - Part B
INDEX CONDITIONS OF CONTRACT
AS 2125-1986 AUSTRALIAN STANDARD GENERAL CONDITIONS OF TENDERING AND FORM OF TENDER
AS 2127-1986 AUSTRALIAN STANDARD FORM OF FORMAL INSTRUMENT OF AGREEMENT
AMENDMENT CONTROL SHEET
  
File Format:  PDF(Acrobat Reader) or Word version doc Document
File Size:  338KB
Tile in English:  general conditions of contract

Full Text Information

Related

Top 10

New 10

PC Version